General Terms and Conditions issued by Koninklijke Metaalunie (the employers’ organisation for small and medium-sized enterprises in the metal industry) referred to as TERMS AND CONDITIONS OF THE METAALUNIE, filed with the Registry of the Court of Rotterdam on 1 January 2019.
Publication of the Koninklijke Metaalunie, P.O. Box 2600, 3430 GA, Nieuwegein.
© Koninklijke Metaalunie
1.1. These Terms and Conditions apply to all offers made by a Metaalunie member, to all agreements that it enters into and to all agreements arising from this, all of which insofar as the Metaalunie member is the supplier or the contractor.
1.2. Metaalunie members who apply these Terms and Conditions are referred to as the Contractor. The other party is referred to as the Client.
1.3. In the event of conflicts between the agreement entered into by the Client and the Contractor and these Terms and Conditions, the provisions of the agreement will prevail.
1.4. These Terms and Conditions may only be applied by Metaalunie members.
2.1. All offers are without obligation. The Contractor is entitled to revoke its offer up to two working days after it has received the acceptance.
2.2. If the Client provides the Contractor with information, the Contractor may assumethat it isaccurateandcompleteand will baseits offer onthis information.
2.3. The prices stated in the offer are denominated in euros, excluding VAT and other government levies or taxes. The prices do not include travel, accommodation, packaging, storage and transport costs, nor do they include costs for loading, unloading and cooperating with customs formalities.
3.1. All information provided to the Client by or on behalf of the Contractor, such as offers, designs, images, drawings and know-how, of whatever nature and inwhatever form are confidential, and the Client will not use it for any purpose other than for the implementation of the agreement.
3.2. The Client will not disclose or reproduce the information referred to in paragraph 1 of this article.
3.3. If the Client infringes one of the obligations referred to in paragraphs 1 and 2 of this article, it will owe an immediately payable penalty of €25,000 for each infringement. This penalty can be claimed in addition to compensation by virtue of the law.
3.4. The Client must returnor destroy the information referred toin paragraph 1 of this article immediately on request, within a period set at the discretion of the Contractor. If this provision is infringed, the Client will owe the Contractor an immediately payable penalty of € 1,000 per day. This penalty can be claimed in addition to compensation by virtue of the law.
4.1. The Client cannot derive any rights from advice and information provided by the Contractor that is not directly related to the contract.
4.2. If the Client provides the Contractor with information, the Contractor may assume that it is accurate and complete when implementing the agreement.
4.3. The Client indemnifies the Contractor against any third-party claims related to the use of advice, drawings, calculations, designs, materials, brands, samples, models and the like provided by or on behalf of the Client.
The Client will compensate the Contractor for all damage suffered by the Contractor, including all costs incurred for defence against these claims.
5.1. Delivery times or implementation periods specified are indicative.
5.2. The delivery time or implementation period only commences once an agreement has been reached on all commercial and technical details, once all the information, including final and approved drawings and the like, is in the possession of the Contractor, the agreed payment (or instalment) has been received, and the other conditions for the contract have been met.
a. there are circumstances other than those known to the Contractor at the time it set the delivery period or implementation period, the delivery period or implementation period may be extended by the time the Contractor needs – taking into account its planning – to implement
the contract under these circumstances;
b. there are contract extras, the delivery period or implementation period may be extended bythe time the Contractor needs – taking intoaccount its planning – to have the materials and parts delivered and to carry out the contract extras;
c. the Contractor suspends its obligations, the delivery period or implementation period may be extended bythe time the Contractor needs – taking intoaccount its planning – to implement the contract after the reason for the suspension no longer applies.
Unless the Client has evidence to the contrary, the duration of the extension of the delivery period or implementation period is presumed to be necessary and to be the result of a situation as referred to above in a to c.
5.4. The Client is obliged to pay all costs that the Contractor incurs or damages that the Contractor suffersasaresult of adelay inthe delivery or implementation period as stated in paragraph 3 of this article.
5.5. Under no circumstances does exceeding the agreed delivery or implementation periodgivethe Client theright tocompensationor to terminate the agreement. The Client indemnifies the Contractor against any third-party claims due to exceeding the delivery or implementation period.
6.1. Delivery takesplace when the Contractor, at its business location, makes the good available to the Client and has informed the Client that the good is at its disposal. From that time onwards, the Client bears the risk of the good in terms of storage, loading, transport and unloading among others.
6.2. The Client and the Contractor may agree that the Contractor will be responsible for the transport. In that case too, the Client bears the risk of, inter alia, storage, loading, transport and unloading. The Client can insure itself against these risks.
6.3. If agoodis exchanged and the Client retainsthe good to be exchanged pending delivery of the new good, the risk of the good to be exchanged remains with the Client until the time that it hands over the good to the Contractor. If the Client is unable to deliver the good to be exchanged in the condition in which it was when the agreement was concluded, the Contractor may terminate the agreement.
The Contractor may pass on to the Client an increase in cost-determining factors that occurs after entering into the agreement. The Client is obliged to pay the price increase immediately on the Contractor’s request.
8.1. If the Contractor fails to fulfil its obligations, this cannot be attributed to the Contractor if this failure is due to force majeure.
8.2. Force majeure includes, inter alia, if third parties engaged by the Contractor – suchassuppliers, subcontractors and transporters, or other parties that the Client is dependent on – do not meet their obligations at all or on time, or circumstances due to weather conditions, natural disasters, terrorism, cybercrime, disruptionof digital infrastructure, fire, power failures, loss, theft or loss of tools, materials or information, roadblocks, strikes or
work interruptions and import or trade restrictions.
8.3. The Contractor is entitled to suspend fulfilment of its obligations if it is temporarily prevented fromfulfilling its obligations to the Client due to force majeure. Once the force majeure circumstances no longer apply, the Contractor will fulfil its obligations as soon as its planning permits.
8.4. If it concerns force majeure and fulfilment is or becomes permanently impossible, or the temporary force majeure circumstances have lasted for more than six months, the Contractor is entitled to terminate the agreement with immediate effect either entirely or in part. Inthose cases, the Client is entitled to terminate the agreement with immediate effect, but only for that
part of the obligations that the Contractor has not yet fulfilled.
8.5. The parties are not entitled to compensation for the damages suffered or to be suffered as a result of the force majeure, suspension or termination as referred to in this article.
9.1. The Client must ensure that all licences, exemptions and other decisions that are necessary to carry out the work are obtained in good time. The Client is obliged to send the Contractor a copy of the aforementioned documents immediately on the Contractor’s request.
9.2. Unless otherwise agreed in writing, the work does not include:
a. groundwork, pile driving, cutting, breaking, foundation work, masonry, carpentry, plastering, painting, wallpapering, repair work or other construction work;
b. making connections to gas, water, electricity, internet or other infrastructural facilities;
c. measures toprevent or limit damage to, of theft or loss of goods present at or near the workplace;
d. removing equipment, building materials or waste;
e. vertical and horizontal transport.
10.1. Changes in the work will in any event lead to contract extras if:
a. it concerns changes in the design, the specifications or the contract documents;
b. the information provided by the Client does not correspond with reality;
c. the estimated quantities deviate by more than 5%.
10.2. Contract extras are calculated on the basis of the price-determining factors that apply at the time the extra work is performed. The Client is obliged to pay the price for the contract extras immediately on the Contractor’s request.
11.1. The Client will ensure that the Contractor can carry out its work undisturbed and at the agreed time and that it is given the necessary facilities for the implementation of its work, such as:
a. gas, water, electricity and internet;
c. lockable dry storage space;
d. the facilities prescribed under the Dutch Working Conditions Act [Arbowet].
11.2. The Client bears the risk and is liable for damage to and theft or loss of goods belonging to the Contractor, Client and third parties, such as tools, material or equipment intended for the work or used for the work, located at or near the place where the work is carried out or at another agreed location.
11.3. Notwithstanding the provisions in paragraph 2 of this article, the Client is obliged to take out adequate insurance against the risks referred to in that paragraph. In addition, the Client must take out insurance for the risk of work related damage with regard to the equipment to be used. The Client must send the Contractor acopy of the relevant insurance(s) and proof of
payment of the premium immediately on request. In the event of damages, the Client is obliged to report this immediately to its insurer for further processing and settlement.
12.1. The work is considered to be delivered in the following cases:
a. once the Client has approved the work;
b. if the Client has put the work into operation. If the Client puts part of the work into operation, then that part is considered to have been delivered;
c. if the Contractor has notified the Client in writing that the work has been completed, and the Client fails toinformthe Contractor in writing that the work has not been approved within 14 days of the day of the notification;
d. if the Client does not approve the work on the grounds of minor defects or missing parts that can be repaired or delivered within 30 days and that do not hinder the commissioning of the work.
12.2. If the Client does not approve the work, it is obliged to in form the Contractor of this in writing, stating the reasons. The Client must give the Contractor the opportunity to deliver the work at a later date.
12.3. The Client indemnifies the Contractor against third-party claims concerning damage to parts of the work not delivered due to the use of parts of the work that have already been delivered.
13.1. In the event of an attributable failure, the Contractor is still obliged to fulfil its contractual obligations, with due observance of Article 14.
13.2. The Contractor’s obligation to compensate damages – regardless of the grounds – is limited to the damage against which the Contractor is covered under an insurance policy taken out byit or on its behalf. However, the scope of this obligation is never greater than the amount paid out under this insurance in the case in question.
13.3. If, for whatever reason, the Contractor does not have the right to invoke paragraph 2 of this article, the obligation to compensate damage is limited to a maximum of 15% of the total contract amount (excluding VAT). If the agreement consists of parts or partial deliveries, this obligation is limited to a maximumof 15% (excluding VAT) of the contract amount for that
part or that partial delivery. If it concerns continuing performance contracts, the obligation to compensate damage is limited to a maximumof 15% (excluding VAT) of the contract amount owed over the last twelve months prior to the losscausing event.
13.4. The following do not qualify for compensation:
a. consequential damages. Consequential damages include inter alia business interruption losses, loss of production, loss of profit, penalties, transport costs and travel and subsistence expenses;
b. damage to property in the care, custody or control of, but not owned by the insured party. Among other things, this damage includes damage caused byor during the performance of the work to goods that are being worked on or to goods that are located in the vicinity of the place where the work is being carried out;
c. damage as a result of intent or wilful recklessness by the Contractor’sauxiliary staff or non-managerial subordinates.
The Client can take out insurance for these damages if possible.
13.5. The Contractor is not obliged tocompensate damage to material supplied by or on behalf of the Client as a result of improper processing.
13.6. The Client indemnifies the Contractor against all third-party claims due to product liability asaresult of a defect inaproduct that has been delivered by the Client to a third party and of which the products or materials supplied by the Contractor are a part. The Client is obliged to
reimburse all the damages suffered by the Contractor in this respect, including the (full) costs of the defence.
14.1. Unless otherwise agreed in writing, the Contractor guarantees the proper execution of the agreed performance for a period of six months after delivery or completion, as detailed in the following paragraphs.
14.2. If the parties have agreed to deviating guarantee conditions, the provisions of thisarticlewill remaininfull force, unless this is in conflict with those deviating guarantee conditions.
14.3. If the agreed performancehas not beenexecutedproperly, the Contractor will decide within areasonable period of time whether it will still perform the work properly or credit the Client for a proportionate part of the contract amount.
14.4. If the Contractor opts to still execute the performance properly, it will determine the manner and time of execution. The Client must in all cases offer the Contractor the opportunity to do so. If the agreed performance (also) included the processing of material provided by the
Client, the Client must supply new material at its own expense and risk.
14.5. The Client is responsible for sending parts or materials that are to be repaired or replaced by the Contractor to the Contractor’s business location.
14.6. The following are for the Client’s account:
a. all transport or shipping costs;
b. costs for dismantling and assembly;
c. travel and subsistence expenses and travel time.
14.7. The Contractor is only obliged to implement the guarantee if the Client has fulfilled all its obligations.
a. The guarantee does not cover defects that are the result of:
• normal wear and tear;
• improper use;
• lack of maintenance or maintenance carried out incorrectly;
• installation, assembly, modification or repairs carried out by the Client or third parties;
• faulty or unsuitable goods originating fromor prescribed by the Client;
• faulty or unsuitable materials or tools used by the Client.
b. No guarantee is given for:
• goods delivered that were not new at the time of delivery;
• inspections and repairs carried out on goods owned by the Client;
• parts that are subject to a manufacturer’s guarantee.
14.9. The provisions of paragraphs 3 to 8 of this article apply by analogy to any of the Client’s claims based on breach of contract, non-conformity or any other basis whatsoever.
15.1. The Client no longer has the right to invoke a defective performance if it has not complained to the Contractor in writing within fourteen days after it discovered or should reasonably have discovered the defect.
15.2. The Client must have filed complaints about the invoice with the Contractor in writing and within the payment term, subject to forfeiture of all rights. If the payment term is longer than thirty days, the Client must have filed its complaint in writing within thirty days of the invoice date at the latest.
16.1. The Client is obliged to take actual possession of the goods that are the subject of the agreement at the agreed location at the end of the delivery or implementation period.
16.2. The Client must cooperate fully and free of charge to enable the Contractor to deliver the goods.
16.3. Goods not taken into possession are stored at the Client’s expense and risk.
16.4. If the provisions of paragraph 1 or 2 of this article areinfringed, the Client will owe the Contractor a penalty for each infringement of € 250 per day up to a maximum of € 25,000, after the Contractor has given notice of default. This penalty can be claimed in addition to compensation by virtue of the law.
17.1. Payment is made at the Contractor’s business address or into an account to be designated by the Contractor.
17.2. Unless otherwise agreed, payments must be made within 30 days of the invoice date.
17.3. If the Client fails to fulfil its payment obligation, it is obliged to comply with a request from the Contractor for a tender of payment instead of the agreed amount.
17.4. The Client’s right to offset its claims against the Contractor or to suspend the fulfilment of its obligations is excluded, unless the Contractor has been granted asuspension of payments or is bankrupt or the statutory debt adjustment scheme applies to the Contractor.
17.5. Irrespective of whether the Contractor has fully executed the agreed performance, everything that the Client owes or will owe it under the agreement is immediately due and payable if:
a. a payment termhas been exceeded;
b. the Client does not fulfil its obligations under Article 16;
c. the Client has filed for bankruptcy or suspension of payments;
d. the Client’s goods or claims have been attached;
e. the Client (a company) is dissolved or wound up;
f. the Client (a natural person) files a application to be admitted to the statutory debt adjustment scheme, isplaced under a guardianship order or has died.
17.6. If payment is delayed, the Client will owe interest on that sum to the Contractor with effect from the day following the day agreed as the final day of payment up to and including the day on which the Client settles the amount in question. If the parties have not agreed on the final day of payment, the interest is due from30 days after the sumhas become due and
payable. The interest is 12%per year, but is equal to the statutory interest if this is higher. For the interest calculation, a part of the month is considered to be a full month. At the end of each year, the amount on which the interest iscalculated will be increased by the interest due for that year.
17.7. The Contractor is entitled to offset its debts to the Client against claims that companies affiliated to the Contractor have against the Client. In addition, the Contractor is entitled to offset its claims to the Client against debts that companies affiliated to the Contractor have against the Client.
Furthermore, the Contractor is entitledtooffset its debts tothe Client against claims against companies affiliated tothe Client. ‘Affiliated companies’ means all companies belonging to the same group, within the meaning of Book 2, Section 24b of the Dutch Civil Code, and a participation within the meaning of Book 2, Section 24c of the Dutch Civil Code.
17.8. For late payments, the Client owes the Contractor all extra judicial costs with a minimumof € 75.
These costs arecalculated on the basis of the following table, i.e., the principal sumplus interest:
on the first € 3,000 15%
on the excess up to € 6,000 10%
on the excess up to € 15,000 8%
on the excess up to € 60,000 5%
on the excess from € 60,000 or more 3%
The extrajudicial costs actually incurred are due if they are higher than the calculation given above.
17.9. If judgment isrenderedinfavour of the Contractor inlegal proceedings, either entirely or for the most part, the Client will bear all costs incurred in connection with these proceedings.
18.1. Irrespective of the agreed payment terms, the Client is obliged to provide sufficient security for payment immediately on the Contractor’s request and at itsdiscretion. If the Client does not comply with thisprovision within the set time limit, it will immediately be in default. Inthat case, the Contractor has the right to terminate the agreement and to recover its
damages fromthe Client.
18.2. The Contractor remains the owner of the delivered goods as long as the Client:
a. has not fulfilled its obligations under any agreement with the Contractor;
b. claims arising from non-fulfilment of the aforementioned agreements, such as damage, penalties, interest and costs, have not been settled.
18.3. Aslong asthe delivered goods aresubject toretention of title, the Client may not encumber or dispose of these goods other than inthe course of its normal business operations. This provision has effect under property law.
18.4. After the Contractor has invoked its retention of title, it may take back the delivered goods. The Client will cooperate fully with this.
18.5. If the Client has fulfilled its obligations after the Contractor has delivered the goods to it in accordance with the agreement, the retention of title with respect tothese goods isrevived if the Client does not fulfil its obligations under an agreement entered into subsequently.
18.6. The Contractor has aright of pledge and aright of retention on all goods that it has or may receive fromthe Client on any grounds whatsoever and for all claims that it has or might have against the Client.
19.1. The Contractor is considered to be the maker, designer or inventor of the works, models or inventions created in the context of the agreement.
The Contractor therefore has the exclusive right to apply for a patent, trademark or model.
19.2. The Contractor will not transfer any intellectual property rights to the Client in the implementation of the agreement.
19.3. If the performance to be delivered bythe Contractor (also) includes providing computer software, the source code will not be handed over to the Client. The Client will only acquire a non-exclusive, worldwide and perpetual licence for use for the computer software solely for the purpose of the normal use and proper functioning of the good. The Client is not
permitted to transfer the licence or to issue a sub-licence. When the Client sells the good to a third party, the licence transfers by operation of law to the acquirer of the good.
19.4. The Contractor disclaims liability for damages that the Client suffers as a result of an infringement of third-party intellectual property rights. The Client indemnifies the Contractor against any third-party claims related to an infringement of intellectual property rights.
The Client may not assign or pledge any rights or obligations pursuant to any articleintheseGeneral Terms and Conditions or the underlying agreement(s), unless it has the prior written consent of the Contractor. This provision has effect under property law.
21.1. The Client is not entitled to cancel or terminate the agreement, unless the Contractor agrees to this. If the Contractor agrees, the Client will owe the Contractor an immediately due and payable compensation equal to the agreed price, less the savings for the Contractor as a result of the termination. The compensation will be at least 20%of the agreed price.
21.2. If the price depends on the actual coststo be incurred by the Contractor (on a cost-plus basis), the compensation asreferred to in the first paragraph of this article is estimated based on the sumof the costs and labour and the profit that the Contractor would have made for the entire contract.
22.1. Dutch law applies.
22.2. The Vienna Sales Convention (CISG) does not apply, nor does any other international regulation that may be excluded.
22.3. The Dutch civil court with jurisdiction in the Contractor’s place of business is authorised to take cognisance of any disputes. The Contractor may deviate fromthis rule governing jurisdiction and rely on the statutory rules governing jurisdiction instead.
These Terms and Conditions constitute a comprehensive translation of the Dutch version of the Terms and Conditions of the Metaalunie as filed with the Registry of the Court of Rotterdamon 1 January 2019. The Dutch version will prevail in the explanation and interpretation of this text.
Feeling comfortable and secure when buying and working with a machine is important. This is why you chose DUMETA®; for quality, durability and optimal usability.
Therefore, DUMETA® grants a three-year warranty on various new DUMETA® machines *, purchased after October 1, 2015.
This guarantee applies only to manufacturing defects not to wear parts oraccessories.
The DUMETA® warranty is not transferable.
This three-year warranty applies to all welding positioners, welding rotators, column & boom manipulators, GIROMATIC®, ROT PRO®, pipe tilting rotators of the following series:
• D-TLP, D-TLP-HE, D-TLP-DC, D-TLP-HE, D-TLP-L, D-TLP-VE, D-TLP-V, D-HB, D-HBE, D-HB-HE, D-BYTN, D-TT, D-DWR, D-DWR-VE, D-TLRS, D-HGZ, D-CHGK, D-HGK, D-TL-HCJ, D-NHCZ, D-JS, D-BD, GIROMATIC®, ROT PRO®, D-TLPR-500, D-GK-1000-PR.
The normal 1 year warranty to manufacturing defects applies to our other products and those of the categories mentioned below including support rollers, chucks, clamping devices, lifting magnets, cantilever racks GUSTOS and tapping machines.
• D-NHTG, D-ZCJ, D-NHK, D-PM, D-MB, D-K, D-D, D-WP, D-SCW, D-KB, D-JS, D-BD
1. This warranty applies only to manufacturing defects related to material or processing errors of a new standard DUMETA® machine that purchased after October 1, 2015. Decisive is the date of purchase on the original invoice.
2. 3 year warranty is only applicable to the new standard machines of the series below and only to manufacturing faults;
• D-TLP, D-TLP-HE, D-TLP-DC, D-TLP-VE, D-TLP-V, D-TLP-L
• D-HB, D-HBE, D-HB-HE
Column & Boom manipulators
• ROT PRO® 90
• ROT PRO® 180
Pipe tilting rotators
3. DUMETA® guarantees that it will repair defects to DUMETA® machines, free of charge during the warranty term, caused by material or processing errors.
4. The 3 year warranty only applies in case of a written notification within 7 days to DUMETA and when presenting / sending the original purchase invoice.
5. If the warranty is claimed, the machine must be sent back to DUMETA® at the expense and risk of the owner. The machine is assessed by DUMETA® and, if necessary, repaired as part of the warranty. Transport and reinstallation are not covered by the warranty.
6. If a material or manufacturing defect occurs during the warranty period, the defective item or the replaced machine becomes property of DUMETA®.
7. The following is not covered by the warranty:
• wear and tear due to use
• defect caused by wear
• defect due to non-compliance with the instructions for use
• defect due to improper use
• defect due to exceptional environmental conditions
• defect due to overload or improper maintenance
• defect due to the use of unsuitable accessories or parts
• if the product has been disassembled, changed or rebuilt
• repairs that were not performed by authorized repairers or DUMETA® or have not been reported beforehand
• slings of the GIROMATIC® rotating system
• rollers of the welding rotators and pipe tilting rotators
8. The warranty applies to the machines mentioned above which are bought and used in Europe. The warranty is not extended or renewed by warranty services / repairs carried our during the warranty period.
9. DUMETA® reserves the right to change the warranty conditions and other conditions without prior notice.
The normal one year warranty to manufacturing defects applies of course to all our other products.